Flow Meter Replacement Project
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
SGMA Prop 68 Grant RFP SVGMD
Flow Meter Replacement Project
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
SGMA Prop 68 Grant RFP SVGMD
Flow Meter Replacement Project
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
SGMA Prop 68 Grant RFP SVGMD
Flow Meter Replacement Project
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
SGMA Prop 68 Grant RFP SVGMD
Flow Meter Replacement Project
REQUEST FOR PROPOSALS FOR CONSTRUCTION CONTRACTOR WORK
SIERRA VALLEY SUBBASIN (5-012.01) SGMA IMPLEMENTATION
CONTRACT DOCUMENTS AND TECHNICAL SPECIFICATIONS REQUEST FOR PROPOSALS (RFP) FOR THE SVGMD FLOW METER REPLACEMENT PROJECT
The Sierra Valley Groundwater Management District invites qualified respondents to submit proposals to provide construction contractor work in association with the SVGMD flow meter replacement project for the Sierra Valley Subbasin (5-012.01) SGMA Implementation. The District received a Proposition 68 DWR Grant to prepare a Groundwater Sustainability Plan with Work Plan “Category (d)” or Monitoring / Assessment to support plan implementation.
To be considered responsive, qualified respondents must electronically submit a written proposal in accordance with the requirements and specifications described in the RFP. The contract document and meter improvement plan can be found on the District's website at: https://svgmd.specialdistrict.org/sgma-prop-68-grant-rfp-svgmd-flow-meter-replacement-project
The Board Clerk will serve as the District’s contact person during the RFP process. Any and all communication regarding this solicitation shall be submitted in writing by email and directed to the Board Clerk, Jenny Gant at sierravalleygmd@sbcglobal.net.
RFP SUBMISSION DEADLINE: November 15, 2021 at 1:00 PM
Questions and requests for clarification pertaining to this project shall be addressed in writing via email prior to November 9, 2021 at 5:00 p.m. PST to: SVGMD Attention: Jenny Gant Email: sierravalleygmd@sbcglobal.net
